Terms of Service

Witsberry provides software development, technical consulting, and "CTO Partner" services. We commit to delivering professional, high-quality code and strategic advice. The specific scope of work, deliverables, and timelines will be defined in a separate Statement of Work (SOW) or Project Agreement signed by both parties.

Your Vision, Your Code.

Upon full payment of all fees associated with a project milestone or final delivery:

• You grant Witsberry a non-exclusive license to use your background IP solely for the purpose of delivering the services.
• Witsberry assigns to you all right, title, and interest in the custom deliverables created specifically for you.
• You own the source code, design assets, and technical documentation in their entirety.

We typically operate on a milestone-based payment structure to ensure transparency and accountability:

• Deposit: A percentage is required to commence work and secure your slot.
• Milestones: Subsequent payments are triggered by the approval of defined deliverables (e.g., Design Approval, Alpha Release).
• Final Payment: Due upon project completion, testing, and handover.

Failure to pay invoices within the agreed timeframe may result in a pause of services or delay in IP transfer.

We warrant that our services will be performed with reasonable skill and care. However, due to the nature of software, we do not warrant that software will be error-free or uninterrupted.

To the maximum extent permitted by law, Witsberry shall not be liable for any indirect, special, or consequential damages, including loss of profits or data. Our total liability is strictly limited to the fees paid by you for the specific service giving rise to the claim.

You agree not to solicit, hire, or engage any Witsberry employee or contractor who has worked on your project for a period of 12 months following the conclusion of the project, without our prior written consent.

These Terms shall be governed by and construed in accordance with the laws of England and Wales. Any disputes shall be subject to the exclusive jurisdiction of the courts of England and Wales.